RUNT t1. OREGON PAC. RY. CO.
481
HUNT II. OREGON PAC.
Ry. Co.
(Oircuit Court, D. Oregon.
October 29,1888.)
2.
DAMAGES-FoR BREACH OF CONTRACT.
The party injured by the breach of a contract is entitled to recover all his damages, including gains prevented, as well as losses sustained, provided such damages may fairly be supposed to have been within the contemplation of the parties when they made the contract. and are certain, both in their nature and in respect to the cause from which they proceed.
The plaintiff sues the defendant for damages on an alleged breach of a contract whereby the former agreed, in consideration of certain payments, to be made as the work progressed, to construct 52 miles of railway for the latter. The defendant sets up a counter-claim for the failure to construct the road, and claims damages therefor: (1) For the loss of the use of the road; (2) for the loss of certain freight which it had made" arrangements" to carryover the road; and (3)for the sum it will cost to complete the roadin excess ofthe contract price. On motion of plaintiff, the last two clauses were stricken out of the counter-claim; the one, as arising on a collateral contract not within the contemplation of the parties, and tile other as being uncertain, and also con· tingent on the future construction of the road by the defendant. (8yllab'/J,8 by the Court;)
SAME,
At Law. Action to recover damages. George H. Williamtl, for plaintiff. John W. Whalley and William T. Muir, for defendant. DEADY, J. The plaintiff, a citizen of Ohio, brings this action against the defendant, a corporation formed under the laws of Oregon, to recover $160,000 damages for an alleged breach of a contract entered into by the on August 8, 1887, whereby the plaintiff, for a consideration therein specified, undertook to construct two sections of the defendant's railway, on the eastern extension thereof, one of 42 miles in length, and the other of 10; the first 20 miles to be completed by November 15, 1887, the next 22 miles by April!, 1888, and the last 10 by May 1,1888. The breach alleged is that the defendant wholly failed to make payments on the work as it progressed, according to the agreement, or to furnish transportation, iron, steel, or ties, as provided therein; wherefore the plaintiff was compelled to give up the performance of the contract after doing $80,000 worth of work thereunder, and did quit the work on December 12, 1887. The answer of the defendant was filed April 5, 1888, and contains a counter-claim, miscalled a "further defense," founded on alleged breach of the contract in question by the plaintiff, wherein it is alleged that the plaintiff, after performing work and labor, and furnishing material to the estimated value of $50,643.56, failed and refused to comply with said contract, and about December 10, 1887, abandoned the same, and notified defendant thereof; that the work is still unfinished, nothing having been done thereon since the abandonment by the plaintiff. The counter-claim concludes with three demands for special damages: v.36F.no.8-31 '
482
.' FEDERAL BEPOk1'ER.
(1) That the work cannot now be completed in less than a year, during which time the defendarit will 'be deprived of the "use and operation" of that portion ofits road, to its damage, $50,000. (2) That the defendant, relying on the good faith of the plaintiff in the premises, made "arrangements" to carryover its road from the eastern terminus of the portion the plaintiff agreed toconst1'uqt "a large amount of freight to and from the seaboard, at Yaquina bay, Or., during the season of 1888, towit, to the amount of $50,000; and that, owing to the failure of the plaintiff to perform his contract" the defendants cannot carry said freight, to its damage, $50,000. (3) That the defendants will be compelled to payout large sums of money, in excess of the contract price to com plete the work that the plaintiff undertook, and in so doing, will be put to a large amount of trouble and expense, to its damage, $100,000. The plaintiff moves to strike out of the counter-claim each of these claims for damages, and the allegations in which they are set forth, becll-use they are (1) "irrelevant and immaterial," and (2) "for conjectural or speculative damages." The questions irlVolved in this motion have been thoroughly argued by counsel. The difficulty in this and like cases Hes, not in the ascertainment of the law of the subject, but the application thereof. 1 Sedg. Dam. 65. Counsel for the plaintiff and defendant both cite and rely on the cases of Griffin v. Colver,16 N. Y. 489, Rnd Snell v. Cottingham" 72111. 161. In the New York case itwas'held that, on a breach of contract to deliver a steam-engine at a certain day, for the purpose of driving a planing-mill and certain other machinery, the ordinary rent or hire which could have been obtained for the use of such mill and machinery, the operation of which was suspended for a week for want of the engine, might be recovered as damages, but not the estimate of what might have been earned by the use of the engine and machinery in the meantime, had the contract been complied with. In the course of an able and interesting opinion in the case, SELDEN, J., states the general rule on the subject as follows: "The party injured is entitled to recover all his damages, including gains prevented as well as losses sustained," subject to only two conditions: "Tha damages must be such as may fairly be supposed to have entered into the confemplation of the parties when they made the contract, 'that is, must be such as might naturally be expected to follow its violation; and they must be certain, both in their nature and in respect to cause from which they proceed." In the Illinois case it was held that, where a contractor fails to construct a railway within the time limited in the contract therefor, but does complete it afterwards, tlie measure of damages for the breach is the value of the use of the road from the timl'l it ought to have been finished until it was done; but not the loss to the owner of the road, by reason of his inability to comply with a contract between himself and a third person for the use of the road fro.m the time it should have been completed, even though the contractor may have known of the existence and
483 exptesslyagreed tosucn' a measure of damages. . . . ' . And still, thedifficultyremain!l: Do the in this case flow directly and naturally frm.l1· the alleged breach of the contral,t? and are they proxoimate consequence thereof, and not speculative or contingent? ' . The tendency of judicial decisions seems to be in favor of allowing a party to show, if he can, that. he has suffered some damage by the breach pf a contract, .either· in gains prevented or losses sustained, whenever such gains or losses directly relate to or arise out of the subject-matter of the contract, and not somethingc011ateral thereto. Ruff v. Rinnldo, 55 N. Y. 664; Hexter v. Knox, 63 N. Y. 561; Hinckley v. Beckwith, 13 Wis. 34; Shepard v. Gas-Light 00., 15 Wis. 349; Davis v. Talcott, 14 Barb. 611; 77; Field, Dam. p. 7, § 10. 1 Sedg. Still, it has been found impracticable to devise any definite and prehensive rule applicable alike to the facts of all cases. Therefore in each case the I11easure of damages must to some extent depend on its own circumstances. Field, Dam. p. 10, § 13. The damages ,claimed on account of the estimated difference in the cost of constructing the road by the defendant and the contract price are, in my judgment, too uncertain to be allowed. It can only be conjectured what the cost of constructing the road some time in the future will be. Owing to the fluctuations· in the price of labor and materials, it may cost more or less to construct the road in 1888-89 than in 1887-88. Besides this, they are contingent. The defendant may never construct the road; and until it does, and necessarily at a greater cost than the contract price, it cannot be said to have sustained any damage by the breach. The contract gave the defendant the right, whenever, in the judgment of its general manager, the work was delayed so as" to im peril" its completion within the time limited, "to assume entire control of the work," and complete it; and"any outlay 80 incurred by the defE1ndant in excess of the contract price of the work shall be a charge against any balance" due the contractor for work done under the contract. This provision in the contract indicates plainly that the parties did not contemplate the payment of any damages for the delay or failure to construct the road, until it was ascertained by the completion of the same what amount, if any, it cost in excess of the contract price. The claim for $50,000 damages, alleged to have been sustained by the defendant's not being able to keep its "arrangement" to carry that amount of freight over the rond in 1888, cannot be allowed. It consists of gains prevented on a collateral contract for the carriage of freight over the road by the defendant. These profits, if realized, would not have been the direct fruit of the contract between the plaintiff anI! the defendant. They could not have been within the contemplation of the parties to the contract of construction at the time they entered into it. The authorities are at one on this point, and particularly the case of Snell v. Co,;. tingham, 8upra. '
484
J'EDERAL REPORTER.
The claim for damages for the' loss of the use of the road presents a different question. Where, from the nature of the case, the value of such use can be shown with reasonable certainty, the authorities favor the allowance of the claim. See Griffin v. Colver, and Snell v. Oottingham,8Upra. · It is impossible to say, on this motion, in advance of the evidence, whether, owing to the condition of this piece of unconstructed road, the defendant can show with reasonable certainty, as in the case of the rent of an ordinary house or mill, what the use of the same was, or would have been, reasonably worth during the time its completion was actually delayed by the failure of the plaintiff to comply with his contract; but I think it ought to be allowed to try-to have the opportunity to do so. The counter-claim does not directly allege that the defendant is the owner or operator of any railway of which the section the plaintiff contracted to construct is a part or extension to the eastward, but so much may be implied from what is alleged. Nor, granting the implication, does it appear therefrom where the western or other terminus of said road is, except as it may be implied from the statement in the second claim for damages, that the defendant had made arrangements to carryover said road from the eastern terminus "of the portion thereof the plaintiff agreed to build" "a large amount of freight to and from the sea-board at Yaquina bay." Under these circumstances, the right of the defendant to damages for the loss of the use of the unconstructed road will depend on the nature of the case made by the evidence. The motion to strike out is denied as· to the first claim :fOI damages, lUld allowed as to the other two.
GOLDSMITH
et ale
'II. HOLMES
et ale 5, 1888.)
(Circuit Oourt, D. Oregon.
1.
N'EGOTIABLB I:NSTRUMENTS-AcTIONS-EvIDENC:m-PAROL-RELATI01'l'SHIP OJ' PARTIES.
The true relation of parties to a negotiable instrument may, as between themselves, be proven by parol, whenever it is necessary to a correct deter· mination of the right or liability of either of them thereon; and this may be done to enable a party to such an instrument ·to maintain an action thereon in the United States circuit court. 1 W. F. Owens, wishing to borrow $10,000 of the plaintiffs. offered to a note therefor, with the defendants as security; and, the plaintiffs consenting. he delivered them a note for the amount, signed by the defendants and paya· ble to his order, which he at the same time indorsed, and also snbscribed a waiver of notice and protest written thereon, and received the amount to his
.. SAME-COURTS-FEDERAL JURISDICTION.
,IOn the B<1missibUity of parol evidence to explain signatures to and indorsements of negotiable instruments, see Harrison v. Morrison, (Minn.) 40 N. W. Rep. 66, and First Nat. Bank v. Gaines, (Ky.) 9 S. W. Rep. 896, and n·ote; Kulenkamp v. Groff, (Mich.) N. W. 57.