Whenever any person supplying labor or material in the prosecution of the work brings an action on such payment bond and the trial judge finds that the defense raised to such action by the contractor or surety was not reasonable, or not in good faith, or merely for the purpose of delaying payment, then the trial judge may, in his discretion, award the claimant a reasonable amount to be determined by the trial judge as claimant’s attorney’s fees in bringing such successful action. Likewise, if the trial judge finds that such action was brought by claimant without just cause or in bad faith, the trial judge may, in his discretion, award the contractor or surety a reasonable amount to be determined by the trial judge as attorney’s fees for defending such action; provided, however, this section shall not affect the right of any person to recover attorney’s fees where provided by contract or bond.
Miss. Code Ann. § 31-5-57
Award of attorney’s fees
Applied in 3 court decisions — leading case Stanton & Associates v. Bryant Const. Co. (1985)
Most recently applied in Tupelo Redevelopment Agency v. Gray Corp. (October 2007)
Laws, 1980, ch. 520, § 4, eff from and after April 1, 1981.
How often courts cite this section
Court decisions citing this, by year. The dip in the last several years is a data-coverage gap, not a real trend — our corpus holds fewer opinions from the most recent years, so recent citations are undercounted.
Current official text: Mississippi Code (LexisNexis). Digitized from the UniCourt Code Improvement Commission public-domain capture. Reproduced from public-domain Mississippi statutes; confirm against the official source for the current text. Not legal advice.